Search Supreme Court Cases
UNITED STATES V. WORMER, 80 U. S. 25 (1871)
U.S. Supreme Court
United States v. Wormer, 80 U.S. 13 Wall. 25 25 (1871)
United States v. Wormer
80 U.S. (13 Wall.) 25
The United States contracted, during the war to suppress the Rebellion, with a dealer in horses for a large number of cavalry horses, he to be paid on the completion of the contract should Congress make an appropriation for that purpose. After the contract had been made, the government issued instructions which were better calculated to protect it against frauds than previous ones had been, and among the regulations was one that the horses should be placed in the inspection yard twenty-four hours before inspecting them, and another that the person appointed as inspector should brand with the letter R on the shoulder, all horses "manifestly intended as a fraud on the government, because of incurable disease or any purposely concealed defect." The contractor threw up his contract and claimed damages, which the Court of Claims allowed him, to the extent which it deemed would make him whole.
This Court reversed the judgment and ordered a dismissal of the contractor's claim, it holding that the new regulations were not unreasonable.
The claimant demanded $15,000 from the government by way of damages for breach of contract. The principal facts
were that on the 26th day of February, 1864, he entered into a written agreement with the chief quartermaster of the Cavalry Bureau to deliver at the government stables in St. Charles, Illinois, by or before the 26th of March, 1,200 cavalry horses, sound and of certain specified ages, height, and quality, and on delivery to be examined and inspected without unnecessary delay by a person or persons to be appointed by the government. Rejected horses were to be removed by the contractor within one day after receiving notice of their rejection. Payment was to be made on completion of the contract, should Congress have made an appropriation for that purpose, or as soon thereafter as funds might be received. Instructions for inspectors of cavalry horses were issued a few days after the date of the contract, which required, amongst other things, that horses proposed for sale to the government should be placed in the inspection yard at least twenty-four hours before inspecting them, and none but the inspector and his assistants were to be allowed to enter the yard or to handle the horses until the inspection was completed. It was also provided that all horses which were manifestly intended as a fraud upon the government because of incurable disease or any purposely concealed defect should be branded on the left shoulder with the letter R. Horses rejected for being under age, in poor condition, or injured by transportation &c., were to be lightly branded on the front part of the fore hoof with the letter R. A large number of other directions were given to inspectors, but these were the principal ones complained of. The claimant applied to have these rules modified or suspended in his case as not having been promulgated when he made his contract, but his application was refused. He therefore threw up his contract, and did not purchase any horses, but alleged that he sustained damages by not being allowed to perform his contract untrammeled by the new regulations.
The Court of Claims found that the regulations materially changed and modified the contract by throwing upon the claimant, in its performance, increased delay, greater expense, and largely augmented risk, and therefore they
gave judgment in his favor for such damages as would make him whole, which they estimated at $9,000. The United States appealed.
Official Supreme Court caselaw is only found in the print version of the United States Reports. Justia caselaw is provided for general informational purposes only, and may not reflect current legal developments, verdicts or settlements. We make no warranties or guarantees about the accuracy, completeness, or adequacy of the information contained on this site or information linked to from this site. Please check official sources.