Search Supreme Court Cases


U.S. Supreme Court

United States v. Brooks-Callaway Co., 318 U.S. 120 (1943)

United States v. Brooks-Callaway Co.

No. 366

Argued January 4, 1943

Decided February 1, 1943

318 U.S. 120


Under the proviso to Article 9 of the Standard Form of Government Construction Contract, which provides that the contractor shall not be charged with liquidated damages because of delays due to unforeseeable causes, including floods, the remission of liquidated damages is not warranted where the "flood" was not unforeseeable, but was due to conditions normally to be expected. P. 318 U. S. 122.

97 Ct.Cls. 689 reversed.

Certiorari, 317 U.S. 615, to review a judgment against the United States in a suit upon a contract.

Powered by Justia US Supreme Court Center: UNITED STATES V. BROOKS-CALLAWAY CO., 318 U. S. 120 (1943)

Official Supreme Court caselaw is only found in the print version of the United States Reports. Justia caselaw is provided for general informational purposes only, and may not reflect current legal developments, verdicts or settlements. We make no warranties or guarantees about the accuracy, completeness, or adequacy of the information contained on this site or information linked to from this site. Please check official sources.